Level 1 Clean Up
Resume:
Cherry Hill, Nj *****
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
PRODUCT SPECIFICATIONS
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
Buyer(s) listed above hereby jointly and severally agrees to purchase the goods and/or services listed on the accompanying specification sheets, in accordance with the prices and terms described in the Custom Remodeling and Improvement and the Product Specifications
(collectively, this “Agreement”).
Windows - Ultraview inclusions: Beveled exterior frame with slimline look, Fusion welded frame and sashes, Limit lock on double hung windows, dual-fin wool pile weather stripping, cam-action lock, special formula uPVC, Certa-Force balance system on double hung window, Integral lift rail, Intercept stainless steel spacer, reinforced meeting rail and bottom sash rail,, Dura-Sill engineered sloped sill, Soft-Seal straddle gasket, exterior custom capping, installation by factory certified crew, clean up and haul away of all job related debris. It is agreed and understood by and between parties that the Product Specifications, along with the Custom Remodeling and Improvement Agreement, constitutes the entire understanding between the parties, and replaces any and all prior negotiations, representations, or agreements, either written or oral. The Product Specifications may not be changed, modified, or varied in any way unless such changes are in writing and signed by both Buyer(s) and Window Nation, Inc. Buyer(s) hereby acknowledge that Buyer(s) has read the Product Specifications. November 18, 2018 www.windownation.com Page 1 of 4 Signature of Exterior Design Consultant
Karl Fulton - License # (null)
Signature
I have read and received each page of this 4 page Product Specification. Window Nation Buyer(s)
YOU, THE BUYER(S), MAY CANCEL THIS TRANSACTION AT ANY TIME PRIOR TO MIDNIGHT OF THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION. SEE THE ATTACHED NOTICE OF CANCELLATION FORM FOR AN EXPLANATION OF THIS RIGHT.
2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
PRODUCT SPECIFICATIONS
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
Work Order Details:
Model: Ultraview W:35" H:59" Location: Level 1, Kitchen 1 Quantity: • Style: Double 2 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Model: Ultraview W:35" H:35" Location: Level 1, Kitchen Sink 2 Quantity: • Style: Double 1 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Model: Ultraview W:35" H:59" Location: Level 1, Dining Room 3 Quantity: • Style: Double 2 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Model: Ultraview W:35" H:59" Location: Level 1, Living Room 4 Quantity: • Style: Double 2 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
November 18, 2018 www.windownation.com Page 2 of 4 2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
PRODUCT SPECIFICATIONS
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
Work Order Details (cont.)
Model: Ultraview W:35" H:59" Location: Level 1, Family Room 5 Quantity: • Style: Double 2 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Model: Ultraview W:35" H:59" Location: Level 2, Bedroom 6 Quantity: • Style: Double 1 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Model: Ultraview W:35" H:59" Location: Level 2, Bedroom (master) 7 Quantity: • Style: Double 2 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Model: Ultraview W:35" H:47" Location: Level 2, Bedroom (master) 8 Quantity: • Style: Double 1 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
November 18, 2018 www.windownation.com Page 3 of 4 2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
PRODUCT SPECIFICATIONS
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
Work Order Details (cont.)
Model: Ultraview W:35" H:59" Location: Level 2, Bedroom 9 Quantity: • Style: Double 1 Hung
• Grids: None
• Screen: Half Screen
• Color: Interior White/Exterior White
• Configuration: Equal Sashes
• Glass: Extreme 2 Pane/Low-E & Argon
Special instructions:
Customer is responsible for Removal & Replacement of blinds and window coverings. Customer was made aware inside mount blinds may not be able to go back up as inside mounts. Installation Details:
Window Removal Type: Vinyl New Construction
Exterior Trim: QE Smooth
Exterior Trim Color: White
Sealant: OSI Quad Max
Insulation Around Window: OSI Quad Foam
Factory Certified Installers: Yes
Clean Up and Haul Away: Yes
Additional products needed in the future: No
Customer agrees to allow Window Nation to post a yard sign until 30 days after install: Yes
Year house was built: 1994
EPA Lead Containment Required: No
EPA Lead Testing Required: No
HOA Approval Required: No
November 18, 2018 www.windownation.com Page 4 of 4 2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
CUSTOM REMODELING AND IMPROVEMENT AGREEMENT
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
Buyer(s) listed above hereby jointly and severally agrees to purchase the goods and/or services of Window Nation, Inc.
("Contractor") in accordance with the prices and terms described in this 6 page document and the Product Specifications, which are incorporated as part of the Agreement (collectively, this "Agreement"). This Agreement represents a cash sale of goods and services. Buyer(s) agrees to pay the cost of the goods and services purchased as described herein, regardless of timing or approval of any financing Buyer(s) may seek for their purchase. Sale Total $9,704.00
Setup & Disposal Fee $149.00
Permit Fee $0.00
Total Sale Price $9,853.00
Down payment - Check 5824 $3,202.00
Balance Due $6,651.00
COD (Payable at time of install) $6,651.00
Amount Financed $0.00
Estimate Project Start: 6-8 Weeks
Buyer(s) acknowledge that definite start and completion dates are NOT of the essence. Delays beyond Contractor’s control not included in calculating timeframes. See Section 5 of the Terms and Conditions.
This Agreement constitutes the entire agreement and understanding between the parties, and this Agreement replaces any and all prior negotiations, representations, or agreements, either written or oral. No amendment, modification or waiver of this Agreement shall be valid or effective unless in writing and signed by both parties. Buyer(s) hereby acknowledge that Buyer(s) 1) has read the entire Agreement and has received a completed, signed, and dated copy of this Agreement, including the two accompanying Notice of Cancellation forms, on the date first written above and 2) was orally informed of his/her right to cancel this transaction.
Buyer(s) also agrees and understands that if Buyer(s) finance the work with a third-party, the terms of that financing will be contained on separate documents, including any finance charge. Price includes all discounts and promotions.
Signature of Exterior Design Consultant
Karl Fulton - License # (null)
Signature
I have read and received each page of this 5 page Agreement. Window Nation Buyer(s)
YOU, THE BUYER(S), MAY CANCEL THIS TRANSACTION AT ANY TIME PRIOR TO MIDNIGHT OF THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION. SEE THE ATTACHED NOTICE OF CANCELLATION FORM FOR AN EXPLANATION OF THIS RIGHT.
November 18, 2018 www.windownation.com Page 1 of 5 2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
CUSTOM REMODELING AND IMPROVEMENT AGREEMENT
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
November 18, 2018 www.windownation.com Page 2 of 5 TERMS AND CONDITIONS
1. Description of the Work to be Performed: Window Nation, Inc. ("Contractor") agrees to do the described work noted on the front of the document (the "work") at the job location (the "Property") for the customer ("Owner") identified in this contract (the "Agreement"). 2. Electronic Contract: A contract is an agreement reached between two or more parties, which is legally enforceable in accordance with specific requirements. Online and/or Electronic Contracts are as valid and enforceable as a paper contract. For purposes of the Window Nation Contract, an online signature is intended to be as binding and as enforceable as a signature on a paper version of the contract. Owner agrees that Contractor's electric-contracts, which are signed with an online signature, is fully enforceable and subject to the same requirements and restrictions as a written contract. 3. Payment of Funds and Deposit: Owner agrees to pay Contractor a deposit as noted on front of this Agreement at the time of the execution of this Agreement and to pay the balance due, as reflected in the final invoice prepared by Contractor ("the invoice"), upon completion of installation. Presentation of the invoice is notice of Owner that Contractor considers the Work complete. All payments made pursuant to this Agreement shall only be made to Contractor. 4. Late Payment / Finance Charge: Any funds owed greater than thirty (30) days beyond the Completion Date are subject to a service charge of one and one-half percent (1.5%) per month interest on the unpaid balance. The definition of Completion Date is the date in which the original install was performed. The need to service the job after the date of the original install does not affect the Completion Date.
5. Customer No Show at Measure or Installation: A customer no show occurs when Owner is not at home at a prescheduled final measure appointment or product installation, and does not provide adequate notice to Contractor of intent to reschedule measure or installation. Notice will only be deemed adequate if Owner contacts Contractor a minimum of 24 hours prior to scheduled appointment. Same day notification is not adequate notice. If adequate notice is not provided and Owner is not home at the time of the prescheduled final measure appointment, Owner agrees to pay Contractor a $75 missed measure fee, which will be due at the completion of the job, and payment of which will be a prerequisite to activating Owner's warranty. If adequate notice is not provided and Owner is not home at the time of the prescheduled installation appointment, Owner agrees to pay Contractor a $350 missed installation fee, which will be due at the completion of the job, and payment of which will be a prerequisite to activating Owner's warranty. If these fees become due, they must be paid in by cash, check, money order or credit card and cannot be added to any financed amount. These fees also do not impact the validity of the original contract, which remains fully in effect. 6. Work Schedule: Contractor agrees to perform the Work in good and workmanlike manner with reasonable dispatch in accordance with the specifications listed above. Contractor is responsible for establishing scheduling and sequencing of the work to be performed. Contractor shall endeavor to actually commence Work (the "Actual Start Date") in accordance with the dates set forth on the front of this Agreement. The Actual Start Date may be altered by Contractor for reasonable delay. Reasonable delays include, but are not limited to, non-delivery, discontinuance, default in shipment by a supplier in whole or in part, loss in transit, strikes, lockouts, weather or other causes beyond Contractor's control. Owner must schedule an installation date within fourteen (14) days after the windows arrive in the warehouse for no more than thirty (30) days after arrival. 7. Materials: All materials shall remain the property and title of Contractor until fully paid by owner. All surplus materials shall remain the property of Contractor unless, at Contractor's option, are turned over to Owner upon the completion of the work. Contractor is not responsible for replacement of any lumber, sheathing, trim or rotted wood, or replacement parts in excess of the agreed amount unless specified in this Agreement.
8. Changes in Contract: Owner hereby expressly authorizes any of the joint signatories, if there are any, or any of his agents, servants, employees, attorney-in fact, or personal representatives to execute and deliver to Contractor any additional changes to this Agreement by a change order (Change Order). Such Change Order shall be binding and conclusive on said Owner. Owner hereby acknowledges that any Change Orders requested by Owner and approved by Contractor pursuant to this section of this Agreement, shall be paid per the terms of Section 2 of this Agreement. Any changes made to this Agreement as required by regulatory agencies will be at additional cost to Owner, unless such changes or additions are cited in this Agreement. Furthermore, by signing this Agreement, Owner acknowledges that no change has been made to this Agreement by any salesperson or other agent on behalf of Owner. Such changes to this Agreement may only occur if a Change Order exists that has been approved by Contractor. Electronic Change Orders with an electronic signature are as enforceable as a written change order with a written signature. Verbal requests for changes do not adequately result in a Contractor approved Change Order.
2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
CUSTOM REMODELING AND IMPROVEMENT AGREEMENT
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
November 18, 2018 www.windownation.com Page 3 of 5 TERMS AND CONDITIONS (cont.)
9. Owner's Responsibilities:
a. Owner warrants to Contractor that he is the legal owner of the Property. Owner agrees to provide to Contractor, at no charge, electric power and water for construction purposes. Owner acknowledges that the removal of permanently attached building materials often disturbs and vibrates the existing property. The debris generated from this Work and other related procedures to this Work may cause inconvenience or discomfort, which is normal construction conditions, and not Contractor negligence. These normal construction conditions may include, but are not limited to minor interior cracks, dusting or flaking of wall paint, debris falling in an attic, potential disturbance and/or damage to shrubbery and lawns, and divots in driveways. As a precaution, Owner is responsible for removing from walls or ceilings, items such as, but not limited to, chandeliers, paintings, plates and other breakable items. Furthermore, Owner shall lock away or secure other items of value in or on the Property. Owner is responsible for local building permit fees required for the work. Owner is responsible for the fees and costs associated and required for any local building permit. Owner or authorized representative of Owner must be present at the completion of Work to review the completed Work and address final payment funds. b. On occasion Contractor will discover circumstances after the original contract is signed that will increase the cost of the materials or labor on the job, such as damaged or rotten wood that could not be determined until the time of measure or installation. If it is determined that such circumstances exist, Owner shall either repair any unforeseen circumstances within seven (7) days or direct Contractor to perform the necessary repairs at a mutually agreed upon additional cost, which will be documented and signed by Owner, and due upon the completion of the project.
c. Owner shall remove all drapes, blinds and window treatments of whatever nature, kind or size prior to Contractor performing any Work. Contractor shall not be responsible for the removal of, or damage to, such drapes, blinds or window treatments due to Owner's failure to comply with this provision. Contractor shall not be responsible for any window covering fit after the installation of windows. Owner shall remove any air conditioning units prior to Work. Contractor shall not be responsible for the removal or reinstallation of, or damage to, window air conditioning units or for proper fit of such unit into replacement window. Owner acknowledges that Contractor shall not be responsible for painting touching up and/or plastering existing walls and/or woodwork after installation of the windows provided for in this Agreement. Owner shall be responsible for having any existing security systems reactivated and/or rewired after installation of new windows and/or vinyl siding. Contractor shall not be responsible for any expenses incurred by Owner for such existing security systems and/or wiring.
d. In the event Owner's homeowner's association approval is required, Contractor shall provide Owner with information regarding the details of the work to be done under this Agreement. It shall be the Owner's responsibility to promptly and diligently submit the information and obtain approval for the design of the Work to be done and to notify Contractor within ten (10) days of the approval/rejection of the request by Owner's homeowner's association. e. Owner shall move all existing furniture at least three feet away from windows being replaced prior to the installation date. Contractor shall not be responsible for moving furniture or damage to furniture due to failure of Owner to comply with this provision. f. Owner acknowledges that if this Agreement is for the purchase and installation of both replacement windows and vinyl siding, Owner shall pay the balance due and owing for the sale and installation of replacement windows at the completion of the installation of the replacement windows and shall pay the balance due and owing for the sale and installation of vinyl siding at the completion of installation of the vinyl siding.
g. By signing this Agreement, Owner(s) hereby authorize Contractor and/or its designee(s) to make whatever inquiries it or they deem necessary in connection with this Agreement, including but not limited to the procurement of credit reports from consumer reporting agencies. Furthermore, Owner agrees that such information procured in relation to this Agreement, including this Agreement, shall remain Contractor's property regardless of the ultimate outcome of the Agreement h. Owner represent and warrants that he, she or they have the present ability to pay in full the amount of money due Contractor under this contract. Allowing the custom windows to be measured, built and/or installed is an acknowledgement by Owner that they are able to pay Contractor at the completion of the project. In the event Contractor determines, in its sole and absolute discretion, that Owner may be unable to pay any amount when due, Contractor reserves the right to stop all work and remove all uninstalled supplies and/or goods and equipment from the Property until the entire unpaid balance of the Contract price has been either paid to Contractor or places in escrow depending on the rules and regulations of the governing body. 2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
CUSTOM REMODELING AND IMPROVEMENT AGREEMENT
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
November 18, 2018 www.windownation.com Page 4 of 5 TERMS AND CONDITIONS (cont.)
i. Should Owner fail to adhere to the responsibilities presented in Section 9, which in turn results in the inability to proceed with the scheduled installation, Owner agrees to pay Contractor a $350 missed installation fee, which will be due at the completion of the job, and payment of which will be a prerequisite to activating Owner's warranty. If this fee becomes due, it must be paid by cash, check money order or credit card and cannot be rolled into any financed amount. This fee also does not impact the validity of the original contract, which remains fully in effect.
10. Cancellation of Agreement: Should Owner cancel this Agreement for any reason by providing the Notice of Cancellation (as otherwise defined herein) prior to the end of the rescission date of this Agreement, Contractor shall return to Owner all payments made under this Agreement within ten (10) days of receipt pf the Notice of Cancellation of this Agreement which is incorporated herein and made a part hereof. Should Owner cancel this Agreement for any reason after the end of the rescission date of this Agreement, Owner agrees to pay Contractor the following sums as liquidated damages, which the Parties hereto agree is a fair and reasonable amount incident to the cost and expenses incurred by Contractor in connection with this Agreement. If Owner cancels this Agreement after the end of the rescission date but before the windows are ordered, Owner agrees to pay Contractor thirty percent (30%) of this Agreement's Sales Total forthwith; or should Owner cancel this Agreement after product has been ordered, Owner agrees to pay Contractor sixty percent (60%) of this Agreement's Sales Total plus a proportionate share of all Work performed or product ordered. Contract is not subject to any cancellation period of signed in showroom. Buyer's and Co-Buyer's Right to Cancel are not affected by the use of an electronic contract, which is enforced with an electronic signature. 11. Default: Owner shall be in default of this Agreement at any time he does not tender payments as listed in section 3 of the Terms and Conditions of this Agreement. Upon Owner's default, Contractor may immediately discontinue Work and the entire balance due shall be immediately due and payable. Waiver or indulgence of any default shall not operate as a waiver of any default on future occasions. 12. Contractor Warranty: Except as otherwise provided herein, in order for any warranty to be effective against Contractor or any other party, Owner must (a) have paid all sums owed to Contractor under this Agreement, (b) provide by immediate, but not later than ten (10) days, written notice by certified mail to Contractor upon discovering any defect or failure of the Work performed and (c) not have in anyway altered or repaired any of the Work performed by Contractor. Long-term warranties provided by the manufacturer will be assigned, to the extent assignable, to Owner upon payment in full for Work performed by Contractor. Any warranties provided for in this Agreement shall begin to run on the Completion Date. Contractor's warranty shall be limited to warranty on labor. 13. Mold: Moisture that has entered into the Property may result in the existence, development or growth of mold, mildew, fungi or other similar microbial conditions (Collectively "Moldï ). Contractor has no experience, expertise, or information regarding Mold or the detection of Mold. Any detection of Mold after Contactor performs work will have to be verified by an independent third party as to the actual presence of Mold as well as the likely cause of such Mold before determining responsibility for the removal of such Mold. The independent Third Party must be agreed upon by both Contractor and Owner. 14. Use of Photos: Owner gives Contractor consent to take photographic pictures, videos or other likenesses, before, during and after the completion of the Work. Owner consents to allow Contractor to use photos, videos and other likenesses for promotional purposes, including but not limited to Contractor's website. 15. Outside Financing: If the Work is financed through an outside lending agency, Owner agrees to execute and deliver necessary finance papers, mortgage, or other forms required by the lending agency in advance of commencement of the Work. Upon notice of the Substantial Completion of the Work, Owner will execute a completion slip if required. 16. Contractor's Right to Cancel: In the event that Contractor determines that this Agreement cannot be performed as intended by the parties due, for example, to incorrect pricing, unforeseen structural defects, or pre-existing conditions to Owner's property, Contractor may cancel this Agreement within thirty (30) days of its execution, notify Owner of such cancellation in writing, and return all money paid by Owner.
17. Entire Agreement: This Agreement constitutes the entire agreement between the Parties. Contractor is not liable for nor bound in any manner by any statements, representations, warranties, collateral or otherwise, or promises made by any person representing or proposing to represent Contractor unless such statements, representations, or promises are set forth in this Agreement. Any modification of this Agreement must be in writing and signed, electronic or handwritten, by the Parties. Electronic signatures are as enforceable as handwritten signatures.
2020 Springdale Rd, Ste 300
Cherry Hill, Nj 08003
Date of Agreement:
November 18, 2018
Sales: 866-***-****
License #: 201-***-**** Service: 866-***-****
CUSTOM REMODELING AND IMPROVEMENT AGREEMENT
Buyer’s Information and
Description of Property:
Michael Seward
Chrissy Osborne
43 Lochview Dr
Bear, DE 19701
Buyer Contact Information:
302-***-**** Primary Mobile
Buyer Email Information:
******.*******@*****.***
November 18, 2018 www.windownation.com Page 5 of 5 TERMS AND CONDITIONS (cont.)
18. Severability: If any provisions, paragraphs, or subparagraph of this Agreement is adjudged by any court to be void or unenforceable in whole or in part, this adjudication shall not affect the validity of the remainder of this Agreement. Each provision of this Agreement is severable from every other provision, and constitutes a separate and distinct covenant. 19. Choice of Law; Jurisdiction: This Agreement shall be construed in accordance with the laws of the State of Maryland. Any legal action to be instituted hereunder shall be filed in the appropriate court where the property is located. 20. Interpretation: No provision of this Agreement is to be interpreted for or against any party because that party or such party's legal representative drafted such provision.
21. Insurance: Window Nation, Inc. maintains liability insurance covering personal injury in an amount not less than $50,000 and insurance covering property damage caused by the work performed in an amount not less than $50,000. Included in the contract is a copy of our liability insurance policy for the home owner's records. 22. Registration Number: The official registration number of Window Nation, Inc. can be obtained from the Pennsylvania Office of Attorney General's Bureau of Consumer Protection by calling toll-free within Pennsylvania 1-888-***-****. Registration does not imply endorsement.
23. Subcontractor: At the time of Sale Window Nation may not know which subcontractor is needed to complete your project. If you purchase Bellevue windows the subcontractor will be Alside Supply Center. 300 Constance Dr. #1, Warminster, PA 18974, 215-***-****. If you are purchasing Fortis, GrandView or Georgetown windows the subcontractor will be Vytex Windows, 2516 Metropolitan Drive, Feasterville (Trevose), PA 19053, 301-***-****. If you are purchasing Platinum LS, Imperial LS, Envision or Ultraview windows, the subcontractor will be Soft-Lite Windows, 300 S. Gulph Rd., King of Prussia, PA 19406, 610-***-****. All other subcontractors will not be known at the time of sale. Subcontractors will be assigned after the contract is turned into management for review.
Owner acknowledges that they have been advised of and agree to
Contact this candidate